In Ybarra v. Greenberg & Sada, P.C., 2018 CO 81, 2018 Colo. LEXIS 828 (Oct. 15, 2018), Francis Ybarra (Ybarra) filed a complaint against the law firm retained by State Farm Auto Insurance Company (State Farm) to pursue subrogation against Ybarra. In his suit, Ybarra alleged that the law firm violated Colorado’s Fair Debt Collection Practices Act (FDCPA) when it secured a default judgment against Ybarra. The Supreme Court of Colorado, agreeing that State Farm’s subrogation claim was not a transaction giving rise to a debt within the meaning of the FDCPA, held that the trial court properly dismissed Ybarra’s complaint for failure to state a claim. Continue reading
Category Archives: Colorado
Colorado Requires Privity to Pursue Warranty of Suitability Claim Against Developer
In Forest City Stapleton, Inc. v. Rodgers, 393 P.3d 487 (Colo. 2017), the Supreme Court of Colorado considered whether a home buyer needed privity of contract to pursue an implied warranty of suitability claim against a developer who sold a vacant lot to a professional builder. Finding that that warranty of suitability claims are contractual claims, the court held that the home buyer needed to be in privity of contract with the developer.
Applying the Statute of Repose for Construction Claims, Colorado’s Supreme Court Finds Third-Party Claims Timely-Filed
In Goodman v. Heritage Builders, Inc., 390 P.3d 398 (Colo. 2017) (en banc), the Supreme Court of Colorado clarified the parameters for timely-filing third-party claims for indemnification or contribution in construction defects cases. The court held that C.R.S. § 13-80-104(1)(b)(II) – addressing when a party can file third-party indemnification and contribution claims – controls over the two-year statute of limitations period set forth in C.R.S. § 13-80-102 and the six-year statute of repose period in C.R.S. § 13-80-104(1)(a). Thus, in Colorado, so long as third-party claims are brought during the litigation or within ninety days after the date of judgment or settlement, such claims should be timely.
In Goodman, Heritage Builders, Inc. (Heritage) acted as the general contractor for a home sold to Karen and Courtney Lord (collectively, the “Lords”). The county issued a certificate of occupancy for the home in September 2006. In November 2011, the Lords sold the home to Richard Goodman (Goodman), who discovered alleged construction defects in the home between March and June 2012. In July of 2013, Goodman sent Heritage informal notice of his claims. He sent them a formal notice of claim – as required by Colorado’s Construction Defect Action Reform Act, C.R.S. §§ 13-20-801 to 31-20-808 – in October of 2013. Thereafter, Heritage sent a notice of claim letter to Studio B Architects (Studio B) and Bluegreen, Inc. (Bluegreen), alleging design deficiencies in the home. Subsequently, on December 20, 2013, Goodman filed suit against Heritage and some of its contractors and, in response, Heritage asserted cross-claims and filed a third-party complaint against Studio B and Bluegreen, among others. Arguing that Heritage’s third-party claim against it was barred by the six-year statute of repose contained in C.R.S. § 13-8-104(1)(a), Studio B moved for summary judgment. Bluegreen joined the motion. Finding that Heritage’s claims against Studio B and Bluegreen arose, at the earliest, when Heritage received informal notice of the alleged defects in July of 2013 – more than six years after the home’s date of substantial completion – the trial court held that the statute of repose barred Heritage’s third-party claims against Studio B and Bluegreen. The Supreme Court of Colorado disagreed.
As noted by the court on appeal, in general, construction defect claims are subject to the two-year statute of limitations in C.R.S. § 13-80-102 and the six-year statute of repose in C.R.S. § 13-80-104(1)(a). However, construction defect claims against other parties – “who may be liable to the claimant for all or part of the claimant’s liability to a third person” – are governed by C.R.S. § 13-80-104(1)(b)(II). Pursuant to this subparagraph, notwithstanding the provisions of § 13-80-104(1)(a), contribution and indemnification claims against third-parties may be brought in either: “(1) the construction defect litigation before a settlement or entry of judgment or (2) a separate lawsuit after a settlement or entry of judgment.” Giving the “notwithstanding” language its controlling effect, the court held that, although § 13-80-104(1)(a) incorporates the two-year statute of limitations in § 13-80-102 and contains a six-year statute of limitations for construction defect claims, § 13-80-104(1)(b)(II) is the statute section under which courts determine the timeliness of third-party contribution and indemnification claims. Pursuant to § 13-80-104(1)(b)(II), so long as third-party indemnification and contribution claims are brought during the construction defect litigation or within ninety days following the date of judgment, the claims are timely. Thus, because Heritage brought its third-party claims against Studio B and Bluegreen before any judgment or settlement, the court held that its claims were timely.
The analysis in Goodman serves as a reminder to subrogation professionals that, when deciding whether construction defect-related claims are timely, it is important to review the language of the applicable statute of repose. Where, as in Colorado, there is language in a subsection of the statute of repose indicating that the statute applies “notwithstanding” other statutory sections, subrogation professionals reviewing the statute should accord the subsection containing the “notwithstanding” language appropriate weight.
Colorado’s Court of Appeals Considers How the Statute of Repose Applies in Multi-Contractor Construction Cases
In Sierra Pacific Industries v. Bradbury, 2016 Colo. App. Lexis 1274, 2016 COA 132 (September 8, 2016), Sierra Pacific Industries, Inc. (Sierra Pacific), a subcontractor hired to supply windows and doors on a condominium construction project, filed an indemnification action against Jason Bradbury, d/b/a Bradbury Construction, Inc. (Bradbury), a sub-subcontractor Sierra Pacific hired to install windows and doors. After the trial court granted summary judgment in Bradbury’s favor, the Court of Appeals of Colorado addressed whether Colorado’s six-year statute of repose for construction defect claims, C.R.S. § 13-8-104, barred Sierra Pacific’s claims against Bradbury. In particular, the court addressed the question of whether the tolling period for indemnification claims set forth in § 13-8-104(b)(1) tolls the repose period. The court also addressed how the phrase “substantial completion” should be interpreted in multi-contractor construction cases. Finally, the court considered whether Sierra Pacific could rely on the “repair doctrine” to extend the “substantial completion” date, the date on which the statute of repose begins to run. Sierra Pacific reminds us that, when a defendant invokes a construction defect statute of repose to defeat a plaintiff’s claims, it is important to analyze how the jurisdiction at issue defines the phrase “substantial completion” and how it applies tolling arguments to the statute of repose.